These Terms and Conditions govern your use of CloudComputingConsultingServices.com and, where applicable, any services provided under a separate written agreement. By accessing the website or engaging our services, you agree to these Terms. If you do not agree, please discontinue use of the website.
Definitions
For clarity, the following definitions apply:
- Agreement – The written contract, proposal, or scope document that defines the services.
- Client Content – Materials, data, documentation, or information provided by the client.
- Deliverables – The outputs or results to be provided under the Agreement.
- Company Tools – Internal methodologies, templates, scripts, frameworks, and proprietary resources used in service delivery.
- Final Deliverables – The completed work product delivered to the client.
- Project – The specific engagement described in the Agreement.
- Services – Cloud consulting and related advisory services.
- Third-Party Materials – External tools, software, or resources used in connection with the Project.
Service Delivery
Services are performed according to the milestones and scope defined in the Agreement. We apply professional judgment and commercially reasonable efforts in delivering services.
Delivery timelines depend on the completeness of information provided and timely cooperation.
Proposal and Scope of Work
Proposals remain valid for 30 days from the date issued unless stated otherwise. If not accepted within that timeframe, we may revise and resubmit updated terms or pricing.
Fees, Costs, and Taxes
Unless expressly included in the Agreement:
- Third-party costs are billed separately.
- Approved expenses may be invoiced at cost.
- Clients are responsible for applicable taxes associated with the services.
Payment Terms
Invoices are due within five (5) days of issue unless otherwise agreed in writing. Payment schedules may follow milestone stages outlined in the Agreement.
Late payment may affect delivery timelines.
Scope Changes
All change requests must be submitted in writing.
Minor adjustments that do not significantly affect cost or timing may be accommodated within the existing scope. Substantial changes that alter deliverables or workload may require a supplemental or revised agreement.
Revised proposals remain open for acceptance for fourteen (14) working days unless otherwise specified.
Delays
If delays occur due to client input, approvals, or incomplete information, timelines will be extended on a day-for-day basis.
If delays occur on our side, we will communicate promptly and take reasonable steps to address them.
Events beyond either party’s reasonable control may extend deadlines without constituting a breach.
Evaluation and Acceptance
We conduct internal reviews before submitting deliverables.
Clients have seven (7) working days to review submitted deliverables and request revisions within scope. Revisions will be addressed within a reasonable timeframe.
Client Responsibilities
Clients agree to provide lawful, accurate, and ready-to-use materials. Unless otherwise agreed, clients are responsible for proofreading content and ensuring accuracy.
Timely decisions regarding third-party components and approvals are required to maintain project schedules.
Attribution and Promotion
Unless otherwise agreed, we may include a discreet reference to our involvement in completed work. We may also display non-confidential projects in our portfolio.
Neither party should unreasonably restrict factual references to completed engagements.
Confidentiality
Both parties agree to maintain confidentiality of non-public information shared during the engagement. This obligation does not apply to information that is publicly available or lawfully obtained from other sources.
Confidential information will not be disclosed to third parties without consent, except where required by law.
Relationship of the Parties
We act as an independent contractor. Nothing in these Terms creates a partnership, joint venture, employment relationship, or exclusivity arrangement unless expressly agreed in writing.
We may use subcontractors where appropriate while remaining responsible for service delivery.
Limitation of Liability
Services are provided “as is” to the extent permitted. Our total liability for any claim relating to the services is limited to the amount paid for the specific services giving rise to the claim.
Intellectual Property Rights
Upon full payment, clients receive a non-exclusive, perpetual, worldwide license to use the Final Deliverables as agreed.
Our internal tools, frameworks, and methodologies remain our property unless explicitly transferred in writing. Any modification or derivative use is governed by the Agreement.
Support Services
Ongoing support is provided only if separately agreed and may be billed accordingly.
If deliverables are modified by third parties without our involvement, any related support obligations may not apply.
Updates to These Terms
We may update these Terms and Conditions from time to time. The version published on CloudComputingConsultingServices.com governs current use. Continued use of the website or services indicates acceptance of any updates.